Type:
Open Market
Date Posted:
05/05/2026
Due Date and Time:
05/05/2026 - 09:30
Contact:
glenn_richard@lawd.uscourts.gov
Description:
The U.S. District Court has an office area located at 800 Lafayette St. Suite 3400, Lafayette, La. This area contains approximately 2,200 sq’ and is due for cyclical maintenance upgrades in this space. At this time the Court would like to remove carpeting in these areas and install new carpeting.
This area contains multiple rooms.
Details:
- SCOPE:
Coordination between the court and carpet contractors will be required to phase the work with minimum disruption of schedules to employees and contractors. The Court will remove furniture from areas.
SPECIAL REQUIREMENTS/INFORMATION:
- Existing Carpet
- Remove and dispose of all existing carpet. New carpet will be 24”x24” carpet tile.
- The contractor shall prepare floors to receive industry standard installation of 24”x24” carpet tile.
- The contractor shall supply and provide industry standard carpet meeting the minimum specifications.
- Work areas are always to be kept clean.
- All walls, door frames, and baseboard moldings are to be protected from damage from carpet handling.
- All material and workmanship shall meet building standards.
- All trash is the contractor’s responsibility to be removed from site daily. Building dumpsters shall not be used for disposal.
2. New Carpet
New carpet shall meet or exceed the following commercial carpet specifications.
See Attached file: Specification Shaw Carpet Tile – Entwine 59337 in color Balsa 78103
4. DELIVERABLES
Deliverable 1 Removal and replacement of carpet in 2,200 Sq’ Area
- Remove and dispose carpet.
- Prepare floors to receive industry standard carpet tile standard installation.
- Supply and install carpet brand name or equal to or exceeding the minimum specifications.
Deliverables will be sent FOB: Destination by 5:00pm (CST) on due dates (see Section 3.1) to the following contracting officer’s representative:
Glenn Richard
800 Lafayette St., Suite 3500
Lafayette, La. 70501
